FBO Notice Date 05/24/18
BIDS Reference Number 1234
Document Type: Amendment
Pumps & Compressors

Department of the Army, Army Contracting Command, ACC - NJ (W15QKN), 07806-5000

43 -- CIRCULATOR PUMP REPLACEMENT SOL W15QKN-18-Q-1085COMBINE DUE 052918 POC RASHIDA FUNCHES, Phone 6095622576, Email RASHIDA.D.FUNCHES.CIV@MAIL.MIL
SCOPE OF WORK

99th Readiness Division
Directorate of Public Works
Fort Dix, New Jersey 08640


17 January 2017
Project Name: Circulation Pump Replacement
Project/CSS #: CSS#5927
Project Location: T/SGT Vernon McGarity Memorial USARC
99 Soldiers Lane
Coraopolis, PA 15108

Project POC: PRI: RFOS/QAR: Randy Baker Wk 412-604-8274 Cell 609-414-1835
Project POC/ALT: AFOS: Tim Peters Wk 412-604-8272 Cell 724-689-7893
Engineering Tech: Lee Grafton Wk 412-604-8271 Cell 740-424-6290
HQ Engineer Tech: Jim Partyka Cell 609-500-5107

1. GENERAL CONTRACTOR:

1.1. Shall furnish all plant, labor, equipment, materials, transportation, supervision and technical expertise to perform requirements in accordance with the specifications and allotted period of performance described in this Scope of Work (SOW).

1.1.1. Shall provide their own storage shed or trailer for on-site office accommodations and for storing of equipment and material. The "On-Site Government Quality Assurance Representative" (QAR) will assign the contractor a location for placement of their shed or trailer upon request.

1.2. Shall verify all measurements and specification requirements at the on-site visit prior to starting the project. No extra compensation shall be allowedfor the contractor who does not attend the on-site visit and who does not appreciate the difficulty of the contract specifications. Any discrepancies, ambiguities or changes must be verified and confirmed in writing to the Contracting Officer, Contracting Officer Representative (COR), and QAR.

1.3. Shall furnish all submittals for equipment and/or materials that vary from requirements of this SOW. All submittals are required to be turned in and approved by the QAR 30 days prior to ordering any of those materials.

1.3.1. Shall provide, unless otherwise specified, new and unused materials and/or installed equipment in the original manufacturer's packaging. All materials stored on the job site are subject to inspection by the QAR and must be protected from the elements at all times.

1.4. Shall not perform any portion of this contract without notice to proceed. Shall not commence work prior to the Government COR/QAR pre-construction meeting. Shall notify the COR/QAR a minimum of 72 hours prior to commencing work andprior to completing work on this contract.

1.5. Shall submit, prior to commencing any work: A current Certificate of Insurance (Prime and Subs); a letter appointing a construction superintendent; a schedule of operations. The construction schedule shall be subject to change so Contractor's operations do not conflict or otherwise disrupt normal operations ofthe Government in the facility involved.

1.6. Shall perform the work between the hours of 0730 and 1600 (7:30 AM - 4:00 PM), Monday through Friday (unless otherwise specified), excluding legal holidays. NO EXCEPTIONS, any work on military training/drill weekends or federal holidays must have prior written coordination and approval between the Contractor, Project POC (Primary or Alternate), and the Facility Manager.

1.6.1. Shall submit on company letterhead to the QAR an "Entry AuthorizationLetter" registering all motor vehicles and driver/operators information as required to access individual installations.

1.6.2. Shall ensure all motor vehicles, drivers and operators are qualified,licensed and insured.

1.7. Shall ensure compliance with all applicable Federal, State, and Local Municipal environmental regulations concerning the protection of land, water and resources. Shall apply most stringent regulation requirements to any ambiguities, deviations must be approved in writing by the Contracting Officer or COR. The types and quantities of all hazardous materials brought to the job site shall bereported to the facility/installation environmental officer.

1.8. Shall call/coordinate, prior to any excavation, with local municipalities and the facility utilities section to identify all underground utilities.

1.8.1. Prior to any underground excavation, the contractor shall call and obtain approval from the state in which the work is being performed.

1.8.2. A copy of the approval notification letter or valid authorization number shall be available for inspection at the excavation site.

1.9. Shall be responsible for any damages caused by them or their subcontractors during the performance of this contract, and shall be required to reimbursethe United States Government for the cost of any repairs resulting from those damages, or the Contractor/ Subcontractor shall make the necessary repairs to thesatisfaction of the United States Government.

1.9.1. The contractor shall hold the Government harmless against any liability imposed by a Federal, State, or Local regulatory agency, resulting from the negligent acts or willful misconduct of the contractor to include assessment of acivil or administrative penalty or fine.

1.10. Shall be solely responsible for ensuring compliance with the provisions of this contract by subcontractors. Shall ensure work be performed by workmen skilled in their particular trades, and certified as required by Federal, State and Local laws and/or codes.

1.11. Shall leave the job site in a safe and secure condition at the end of each workday. The contractor shall provide at his/her expense a Dumpster for allconstruction debris, dumping shall also be at contractor expense. The Contractor shall at no time use Government dumpsters.

1.12. Shall clean the job site of all construction debris at the end of eachworking day. The daily clean up will not alleviate the Contractor from the responsibility of the final clean up for acceptance, upon completion of this contract. All debris removed from the job site shall be disposed of properly at an off post/facility landfill of the Contractor's own choice and at the Contractor's expense. Upon request by the by the Contracting Officer or QAR, the Contractor shall provide the name, address, and location of the disposal site, and copies of any manifest from such disposals.

1.13. Shall ensure all work be completed in the negotiated time frame.

2. CONTRACTOR QUALITY CONTROL:

2.1. The Contractor shall provide and maintain an effective quality control program that complies with the Contract Clause (FAR 52.246-12), the below statedquality control requirements and the quality control requirements stated in therespective section of the Technical Specifications. Quality control personnel shall also be charged with the responsibility of policing Contractor's Safety Program.

2.2. The Contractor shall establish a quality control system to perform sufficient inspection and testing of all items of work, including thatof their subcontractors. The quality control system shall ensure conformance with applicable specifications and drawings with respect to materials, workmanship, construction, finish, functional performance, and identification.

2.3. The quality control system will be established for all construction except where the technical provisions of the contract provide for specific Government control by inspections, tests, or other means. The Contractor's quality control system will specifically include the surveillance and tests required in the technical provisions of the contract specifications. For purposes of the above description, shop manufacture or standard products are not defined as construction.

2.3.1. The Contractor's quality control system is the means by which they assure themselves their construction complies with the requirements of the contract plans and specifications. The controls shall be adequate to cover all construction operations, including both on and off-site fabrication.

2.3.2. The Contractor shall not build up or conceal any feature of the work containing uncorrected defects, and payment on deficient items will be withheld until they are satisfactorily corrected or other action has been taken as authorized pursuant to the Contract Clause entitled "Inspection of Construction".

2.3.3. The Contractor's appointed job site supervisor may be used as the Quality Representative (QR). When supplemented by special technicians or testing facilities to perform all specified tests, balancing, adjusting and/or regulating mechanical and electrical devices, equipment and/or systems it will be done in writing. As an option, an industry recognized testing laboratory approved by the Contracting Officer or COR may be used for said testing.

2.3.4. The Contractor is responsible for maintaining an effective quality control system. Recurring deficiencies indicate the system is not adequate and thecontractor's performance is failing to meet Government's minimum acceptable standards. If, in the opinion of the Contracting Officer, an unacceptable number ofdeficiencies are occurring in the contractor's performance, the Contracting Officer may direct the contractor to revise its operations to correct the defectiveperformance. Failure by the contractor to provide acceptable revisions and/or to improve contract performance may result in the termination of the contract fordefault.

2.3.5. In the event the Contractor utilizes the service of a commercial testing laboratory, the Contracting Officer reserves the right to check laboratory equipment for compliance with the standards set forth in the contract specifications and to check the laboratory technician's testing procedures and techniques.

3. GOVERNMENT:

3.1. The Government will provide, when available, electrical power, water and existing utilities at each building required in the performance of this contract at no cost to the Contractor. Temporary extension of power and/or water lines, if necessary, shall be installed at the Contractor's expense.

3.1.1. Contractor owned construction sheds, trailers, offices or other such facilities requiring utility services shall be metered for each utility involved, and all costs involved up to the point of connection to Government owned utility systems shall be at the contractor's expense. Final connection of Contractor supplied service laterals to existing Government owned utility systems will be made at the Contractor's expense.

3.2. Contracting Officer or COR will schedule a pre-performance conference after contract award and prior to commencement of work. The Contracting Officer will notify the contractor of the time, date, and place set for the meeting, which will be held at a location to be designated by the Contracting Officer. At this meeting, the contractor will be oriented with respect to Government proceduresand lines of authority, as well as contractual, administrative, and construction matters. The contractor is required to furnish a current Certificate of Insurance and a letter appointing a construction superintendent at the meeting.

3.2.1. Pre-Construction Conference: Topics will cover but are not limited tothe following:

3.2.1.1. Introduction of Key players: COR/QAR, General Contractor, Job-site Supervisor, Sub-Contractors and using agencies. Other personal that may be in attendance are Environmental, Police, Fire, Safety and Health services, in addition to Distinguished Visitors.

3.2.1.2. Scope of Work (SOW): Brief description of work, modifications to SOW, customer requests for additional work, unauthorized work, facility access andauthorized personnel access.

3.2.1.3. Milestones: Period of performance, start date, schedule, phasing, completion date, work hours desired, weekend work schedule, scheduled outages/interruptions (power, water, roads, alarms, fire protection, HVAC).

3.2.1.4. Materials: Submittals, equipment, construction area, storage area, Government provided utilities, dumpster locations, Barriers (construction fence,silt fence, road blocks, access points to facilities, etc).

3.2.1.5. Administrative: Lines of authority, Wage rate/certified payrolls, Daily reports, Visitor control, Environmental requirements (hazards, dust and noise control), Safety meeting/concerns, Excavation permits, Fire (burn Permits), Police support, Payments, Liquidated Damages

3.2.2. Contracting Officer, COR and/or their QAR may inspect the work at anytime during the contract period, and reserves the right to stop or terminate the contract if all work does not comply with the specifications provided by the manufactures recommendation of this SOW. The presence or absence of the Contracting Officer or QAR shall not relieve the Contractor from strict compliance with these plans and specifications.

3.3. Technical surveillance of workmanship and inspection of materials for work being performed under this contract shall be the responsibility of the QAR. This provision in no way authorizes anyone other than the Contracting Officer tocommit the Government to changes in the terms of the contract. In the event it is determined necessary to designate a QAR for this contract, such designation shall be by a separate letter to the individual selected with a copy furnished tothe contractor.

3.4. The Government, it's Officers and Agents will be free from liability for any negligence occasioned by the Contractor's operations, employees or equipment. In addition, the Contractor will reimburse the Government for any damage and/or loss that occurs as a result of the Contractor's negligent operations, employees or equipment.

3.5. The Government reserves the right to undertake performance by Government forces or other Contractors, the same type of similar work as contracted for herein, as the Government deems necessary or desirable, and to do so will not breach or otherwise violate this contract.

3.6. Federal Holidays (New Year's Day, Martin Luther King JR's Birthday, Presidents' Day, Memorial Day, Independence Day, Labor Day, Columbus Day, Veterans'Day, Thanksgiving Day, and Christmas Day), that fall within the workweek will not be considered workdays. Whenever a holiday falls on a Saturday or Sunday, theproceeding Friday or following Monday respectively will be observed as a holiday. Prior to the contractor performing the work on days or at times other than those specified, the contractor shall submit a written request to the QAR for approval by the Contracting Officer. Requests for deviation shall be submitted no less than 24 hours prior to the time the contractor desires to work.

4. LIFE, SAFETY AND HEALTH REQUIREMENTS: To better provide life, safety and health protection to all contractor employees, on-site personnel, and Governmentpersonnel performing or in any way coming in contact with this contract the specific requirements established here-in will be adhered to at all times:

4.1. 29 CFR 1910: Comply with all pertinent provisions of 29 CFR 1910 General, and with any additional measures the Contracting Officer may determine to be reasonably necessary. Copies of this manual may be obtained from the Superintendent of Documents, U.S. Government Printing Office, Washington, D.C., 20402.

4.2. OSHA: Comply with latest version of OSHA Handbook Rules and Regulations.

4.3. NFPA: Comply with UFC 3-600-01 and the most current edition of the National Fire Codes (NFPA) and installation fire prevention standards. www.nfpa.org/catalog

4.3.1. All open flame/hot work or disconnection of fire protection alarms orsuppression systems require prior written approval/coordination from one of the99th Regional Support Command (RSC) POC's listed on the first page of this document.

4.3.2. Any connection, disconnection or installation of fire protection alarms or suppression systems shall require an acceptance test performed by the contractor and witnessed by the local Fire Prevention Authority having jurisdiction over that facility. In the event the fire alarm system cannot be disconnected (i.e., child development, hospital, etc) a temporary system will be provided and certified by the local Fire Prevention Authority having jurisdiction. Work required to be performed after hours due to the nature of the facility will be at no additional cost to the Government.

4.3.3. All fire alarm system components, including all smoke and heat detectors, shall be protected from dirt, dust and damage during demolition and construction.

4.4. AR 420-90: Comply with Army Regulation 420-90, http://www.usapa.army.mil.

4.5. Lockout / Tag out Procedure: The Contractor shall perform this work in accordance with 29 CFR 1910.147, The Control of Hazardous Energy and the following general requirements.

4.5.1. Preparation: Make a survey to locate and identify all isolating devices to be certain which switches, valves, or other energy isolating devices applyto the equipment to be locked or tagged out. More than one energy source such as electrical, mechanical or others may be involved.

4.5.2. Sequence Of Lockout/Tag out Procedure:

4.5.2.1. Notify all affected personnel that a lockout/tagout system is goingto be used and the reason therefore. The authorized personnel shall know the type and magnitude of energy the machine or equipment uses and shall understand hazards thereof.

4.5.2.2. If the machine or equipment is operating, shut it down by the normal stopping procedure such as depressing stop button, open toggle switch, etc.

4.5.2.3. Operate the switch, valve, or other energy isolating devices so that the equipment is isolated from its energy source. Stored energy such as in charged capacitors, springs, elevated machine members, rotating flywheels, hydraulic systems and other pressurized air, gas, steam, or water systems etc. must be dissipated or restrained by methods such as repositioning, blocking, or bleeding down the stored energy.

4.5.2.4. Lockout and/or tag out the energy isolating devices with assigned individual locks, tags, or additional safety measures as may be required.

4.5.2.5. After ensuring that no personnel are exposed, and as a check on having disconnected the energy sources, operate the push button or other normal operating controls to make certain the equipment will not operate.

CAUTION: Make sure the operating controls are returned to the "NEUTRAL" or "OFF" position after the test.

4.5.2.6. The equipment is now locked out or tagged out.

4.5.3. Restoring Machines Or Equipment To Normal Production Operations:

4.5.3.1. After the servicing and/or maintenance is complete and equipment isready for normal production operations, check the area around the machines or equipment to ensure that no one is exposed.

4.5.3.2. After all tools have been removed from the machine or equipment, guards have been reinstalled, and personnel are in the clear, remove all lockout and tagout devices. Operate the energy isolating devices to restore energy to themachine or equipment.

4.5.4. Procedure Involving More Than One Person: In the preceding steps, if more than one individual is required to lockout or tagout equipment, each shall place his/her own personal lockout or tagout device on the energy isolating devices. When an energy isolating device cannot accept multiple locks or tags, a multiple lockout or tagout hasp shall be used. If a single lock is used to lockout the machine or equipment, the single key shall be placed in a lockout box or cabinet which allows the use of multiple locks to secure it. Each employee shall then use his/her own lock to secure the box or cabinet. As each person no longer needs to maintain his/her lockout protection, only that person shall remove his/her lock from the box or cabinet.

4.6. USACE EM 385-1-1: The Contractor shall be responsible for knowing the Corps of Engineers, Safety and Health Requirements Manual, EM 385-1-1, (use the current version at the time of task order award), and incorporate those general and additional safety requirements into daily working procedures to provide safe working conditions during performance of this contract. Copies of this manual may also be obtained from the Superintendent of Documents. http://www.usace.army.mil/inet/usace-docs/eng-manuals/em385-1-1/toc.htm

4.7. SITE SAFETY PLAN: The Contractor shall submit in writing a Site Safety Plan and present the overall safety program via in-person conference with the Contracting Officer and/or Primary Project POC. The Site Safety Plan shall follow the requirements of the EM 385-1-1 and include all relevant Accident Prevention and Activity Hazard Analyses. The Site Safety Plan shall include provisions to deal with hazardous materials, pursuant to the Contract Clause entitled "Hazardous Material Identification and Material Safety Data".

4.7.1. With respect to hazardous materials, the plan will consist of:

4.7.1.1. A plan for protecting personnel and property during the transport, storage, and use of the materials.

4.7.1.2. An index of hazardous materials to be introduced to the site.

4.7.1.3. Material Safety Data Sheets (MSDS) for materials listed in the index of the plan and not required in the technical section of the specification.

4.7.1.4. Procedures for spill response and disposal.

4.7.2. The Contractor shall not turn in hazardous waste generated during performance of the contract, for disposal by the Government, unless such disposal is explicitly provided for in the contract. If specified in the contract, the Contractor shall provide an MSDS for each hazardous material/waste turned in to theGovernment for disposal.

4.7.3. The Contractor shall not dispose hazardous materials/waste in any dumpster, sanitary sewer, storm sewer or dispose of hazardous materials/waste by any other means on Government property.

4.7.4. The Contractor shall not sign any hazardous waste manifest. Signatureauthority for hazardous waste manifests is delegated only to certain personnel within the Environmental Office. The contractor shall provide copies of all manifests or bills of lading for the transportation and disposal of all asbestos or asbestos containing materials to the Environmental Office.

4.8. HAZARDOUS MATERIAL CONTACT (PCB, Asbestos or Lead Material): If material is encountered which may contain PCB's, hazardous materials, asbestos and/or lead and must be disturbed, DO NOT touch the material. Should the discovery of such suspected material affect the Contractor's planned work schedule, the Contractor shall redirect the work crew to other portions of the unaffected work and modify the schedule at no additional cost to the Government.

4.8.1. Contact/notify an On Site Representative/POC from page one immediately if circumstances appear unusual, unhealthy, or otherwise hazardous.

4.8.2. In writing, address circumstances and concerns to be addressed by theContract Officer, Project POC, Environmental and/or Government Representative regarding the discovery of the suspected material and of any adverse impact the Contractor may expect to incur due to this situation.

4.8.3. On Site Representative, within 14 calendar days, will perform laboratory tests to determine if the material is a hazard. If there is not a danger, the site Representative will direct the Contractor to proceed in the identified area without change. If the material is identified as hazardous, before proceeding, the On Site Representative will determine the most cost-effective means for removal. The hazardous material will be removed, abated or rendered harmless before work commences.

4.9. ENVIRONMENTAL PROTECTION REQUIREMENTS: Provide and maintain strict compliance with all federal, state, county and local environmental protection requirements including but not limited to, water, air, soil, and noise pollution during the life of this contract.

4.9.1. In the event of a spill, initiate containment operations utilizing personnel properly trained and protected for such situations and immediately notify the Contracting Officer and/or On Site Representative/POC from page one.

4.9.2. Plan for and provide environmental protective measures to control pollution that develops during normal construction practice.

4.9.2.1. Prevent oily or other hazardous substances from entering the ground, drainage areas, storm drainage system, or local bodies of water.

4.9.2.2. Keep dust down at all times, including during nonworking periods. Sprinkle or treat with dust suppressants, the soil at the site, and other areas disturbed by operations. Dry power brooming will not be permitted. Instead use vacuuming, wet mopping, wet sweeping, or wet power brooming. Only wet cutting willbe permitted for cutting concrete, and bituminous concrete.

4.9.2.3. Handle generated hazardous waste in accordance with federal, State,county and local regulations including 40 CFR 262.

4.9.3. Plan for and provide environmental protective measures required to correct conditions that develop during the construction of permanent or temporary environmental features associated with the project. Dispose of hazardous waste in strict accordance with federal, State, county and local regulations including 40 CFR 263 and 40 CFR 264.

4.9.4. Make the maximum use of low-noise emission products, as certified by the EPA. Blasting or the use of explosives is prohibited.

4.10. OZONE DEPLETING SUBSTANCES (ODS): The Contractor shall not knowingly vent or otherwise dispose of any ODS in a manner which would permit their releaseinto the environment. ODS's are generally found in refrigerants, fire fighting agents, and solvents.

4.10.1. The Contractor shall use only those products that are approved and listed by the EPA Significant New Alternatives Program (SNAP).

4.10.2. The Contractor shall furnish a material safety data sheet to the Government representative prior to use of any ODS or SNAP product on station.

4.10.3. Class I ODS's: The use on installations or the removal off an installation is strictly prohibited without the prior knowledge and consent of the Contracting Officer.

4.10.4. Class II ODS's: Shall be used only when specified by the Government.

4.10.5. When ODS's of any class are used or saved for reuse, the Contractor shall list this amount in pounds on the "Daily Report To Inspector" form and theContractor's invoice.

4.10.6. ODS's shall be captured and recycled in conformance with all applicable Federal, State, and local regulations.

4.11. SAFETY OFFICER: The Installation Safety Officer will be responsible for monitoring the contractor in the area of safety and accident prevention. Additional information may be provided and Contractor shall comply with the safety rules of the Government installation concerning related activities not directly addressed in this contract.

4.11.1. The Contractor's personnel, when operating motor vehicles, shall not exceed ten (10) miles per hour when passing military troops on the roadways, and abide by post speed limits otherwise.

4.12. OCCUPANCY:

4.12.1. It shall be the Contractor's responsibility to coordinate with QAR to schedule and perform his work in such a manner as to create the least possibleinterference with the conduct of normal activities within the areas.

4.12.2. The Contractor shall not receive any additional compensation due to the conditions brought about by this occupancy and usage of the Government.

4.12.3. Contractors are only authorized to occupy areas in which active construction, maintenance, repair or associated work in the performance of the contract is required to be done.

4.12.4. The Contractor shall not block more than one access of the building at any time, nor shall he disrupt the existing parking arrangement at any of thebuilding parking areas without prior coordination with the QAR.

5. CONDUCT OF EMPLOYEES:

5.1. The Contractor is fully responsible for the performance and conduct of his employees at all times while on post performing under the contract. The Contractor shall not allow any employee to perform work under the contract while under the influence of alcohol, drugs or any other incapacitating agent.

5.1.1. Contractor employees will abide by the DOD Smoking Policy.

5.2. Military police and other law enforcement personnel on post have the right to deny entry to post or remove from post any contractor employee for misconduct which endangers the health or safety of people or property or for reasons of security. In addition, the Post Commander may bar an individual from entering the post under the authority of 18 U.S.C. 1382.

5.3. Removal from post of a contractor employee in accordance with above shall not relieve the Contractor from the requirement to meet all of the terms and conditions of the contract.

6. SECURITY:

6.1. At all times during the performance of work within the facilities, the Contractor and their employees shall remain cognizant of security restrictions existing within the facility. The Contractor's employees shall ensure any doors, windows or access panels which may have been opened for them during the course of the work period are secured at the end of the day.

6.2. The Contractor shall report any incident in which no escort is providedfor scheduled work within secured areas of the building or any occurrence during which an escort leaves the Contractor's employees while within a secure area.

6.3. The Contractor and their employees may store tools and equipment withinthe work area. However, recognize they do so at their own risk even if the areacan be secured.

7. INSPECTOR GENERAL'S (IG) AUTHORITY TO INSPECT CONTRACTORS:

7.1. The Inspector General shall have access to the Contractor's facilities,employees, operations, and records at the site where work is being performed atall times to conduct inspections or for other purposes. Where feasible, advancenotification of an IG inspection or investigation will be provided to the Contractor by the Contracting Officer.

8. DEFINITIONS:

8.1. Where the words "Special Contract Clauses" or "Special Clauses" appear in test provisions, the Technical Specifications, or on contract drawings, it shall be taken to mean "Special Contract Requirements".

8.2. Throughout this contract, the word "indicated", "shown", or "specified"shall mean indicated, shown, or specified in the drawings and/or specified in the specifications.

8.3. Throughout this contract, the words "as directed" "inspected", "selected", or "accepted" shall mean as directed, inspected, selected or accepted by theQAR. The words, "approved" or "authorized" shall mean approved or authorized bythe Contracting Officer. These definitions are provided as guidance for the contractor, and shall service as the governing interpretation when this language appears within the body of this contract and apparently conflicts with the above.

9. APPLICABLE PUBLICATIONS: Those applicable publications that are not listed in the Applicable Publication paragraph of the Technical Specifications sections, but are found elsewhere in the text of those specifications, also form a part of this contract.

10. SUBMITTALS / DELIVERABLES:

10.1. SUBMITTALS: Contractor shall provide submittals to the COR for submittal approval minimum 30 days prior to scheduled installation of any referenced materials substituted in the technical sections herein, unless otherwise noted.

10.1.1. Original and four (4) copies of each submittal shall be provided andsigned by the contractor. Once approved, original and four copies will be stamped "Approved", signed and dated by the COR.

10.1.2. Distribution of submittals: Approved submittals will be included in the deliverables portion as stated in paragraph 10.2 below.

10.2. DELIVERABLES: Send a minimum of 30 days prior to contract completion date original and four (4) copies of ALL final documentation; submittals, certifications, laboratory tests, descriptive data, test reports, required shop drawing, site surveys, and warranties. Send via First Class Mail, FedEx, or UPS to:

99th Readiness Division HQ
Attn: DWP Operations: Contract# __________________
Fort Dix, NJ 08640

10.3. The Contractor shall furnish to the above address the original manufacturer's documentation and four (4) copies demonstrating material proof of compliance requirements in regards to Technical Specifications for this contract.

10.3.1. Certificate of Compliance:

10.3.1.1. Name and address of the Contractor.

10.3.1.2. Project name

10.3.1.3. Location

10.3.1.4. Quantity

10.3.1.5. Dates of shipment or delivery to which the certificates apply.

10.3.1.6. Each certificate shall be signed by an authorized officer of the manufacturing company.

10.3.2. Laboratory Tests: Reports submitted with the certificate shall contain:

10.3.2.1. Name and address of the testing laboratory.

10.3.2.2. Date of the tests to which the report applies.

10.3.3. Samples: The Contractor shall furnish samples of materials for approval, as required by the applicable sections of the technical specifications thatdiffer from the specification.

10.3.4. Descriptive Data: The Contractor shall furnish the manufacturer's descriptive data, installation instructions, and maintenance instructions, for approval, as required by the applicable sections of the technical specifications.

10.3.5. Test Reports: The Contractor shall furnish copies of test reports for approval to demonstrate compliance with the applicable sections of the technical specifications that differ from the specification.

10.3.6. Shop Drawings: Consist of illustrations, schedules, performance charts, instructions, brochures, diagrams, drawings and other information to illustrate and/or demonstrate compliance to the applicable sections of the technical specifications.

10.3.6.1. The Contractor shall furnish for approval, one copy "DRAFT Shop Drawing". Each rendition will be numerically annotated until final approval.

10.3.6.2. The Contractor shall furnish finalized drawing copies "AS BUILTS" and all applicable support data once agreed upon by the Contracting Officer/COR and/or Project POC. Each submission shall include:

10.3.6.2.1. Two (2ea) full size sets of Mylar prints, and Four (4ea) half size paper copy (provide full size paper drawing sets if half size is unreadable).
10.3.6.3.2. Two (2ea) identical copies on optical media discs to include: The drawing sets in both PDF and CAD format (CAD files to be Microstation.dgn files Geo-referenced to WGS84 coordinate system). For smaller projects AutoCAD DWGfiles are acceptable. An electronic copy of the specifications associated with the project. Drawing index in MS Excel listing each drawing title, sheet name, drawing number, sheet number, and electronic file name for the drawings of the project.

10.4. Documentation shall not be construed as relieving the Contractor from furnishing satisfactory material, if after tests are performed on selected samples of the material is found not to meet the specific requirements.

11. TECHNICAL SPECIFICATIONS:

CSS 5927-CIRCULATOR PUMP REPLACEMENT
T/SGT Vernon McGarity Memorial USARC, 99 Soldiers Lane, Coraopolis, PA 15108

PERIOD OF PERFORMANCE: 90 Calendar Days from the Notice to Proceed Date to complete ALL TASKS associated with the Scope of Work.

11.1.1. SECURITY:

11.1.2. AT Level I training. All contractor employees, to include subcontractor employees, requiring access Army installations, facilities and controlled access areas shall complete AT Level I awareness training within 30 calendar days after contract start date or effective date of incorporation of this requirementinto the contract, whichever is applicable. The contractor shall submit certificates of completion for each affected contractor employee and subcontractor employee, to the COR or to the contracting officer, if a COR is not assigned, within5 calendar days after completion of training by all employees and subcontractorpersonnel. AT level I awareness training is available at the following website:http://jko.jten.mil

11.1.3. Access and general protection/security policy and procedures. Contractor and all associated sub-contractors employees shall provide all information required for background checks to meet installation access requirements to be accomplished by installation Provost Marshal Office, Director of Emergency Services or Security Office. Contractor workforce must comply with all personal identity verification requirements (FAR clause 52.204-9, Personal Identity Verificationof Contractor Personnel) as directed by DOD, HQDA and/or local policy. In addition to the changes otherwise authorized by the changes clause of this contract, should the Force Protection Condition (FPCON) at any individual facility or installation change, the Government may require changes in contractor security matters or processes.

11.1.4. For contractors that do not require CAC, but require access to a DoDfacility or installation. Contractor and all associated sub-contractors employees shall comply with adjudication standards and procedures using the National Crime Information Center Interstate Identification Index (NCIC-III) and Terrorist Screening Database (TSDB) (Army Directive 2014-05/AR 190-13), applicable installation, facility and area commander installation/facility access and local security policies and procedures (provided by government representative), or, at OCONUS locations, in accordance with status of forces agreements and other theater regulations.

11.1.5. iWATCH Training. The contractor and all associated sub-contractors shall brief all employees on the local iWATCH program (training standards provided by the requiring activity ATO). This local developed training will be used to inform employees of the types of behavior to watch for and instruct employees toreport suspicious activity to the COR. This training shall be completed within 30 calendar days of contract award and within 5 calendar days of new employees commencing performance with the results reported to the COR NLT 5 calendar days after contract award.

11.1.6. For contracts that require OPSEC Training. Per AR 530-1 Operations Security, the contractor employees must complete Level I OPSEC Awareness training. New employees must be trained within 30 calendar days of their reporting for duty and annually thereafter.

11.1.7. The COR of the project shall inform their employees (contractors) about suspicious activity reporting, iWatch procedures and Antiterrorism/OPSEC Awareness. The COR shall keep proper accountability of their personnel. In the event of an escalated FPCON, there may be extra security measures put in place and it may cause a hindrance to complete the project in the allotted time according to the contract. This will be at no expense to the government. The correct web address for AT Level I is: https://jkodirect.jten.mil Non CAC card holders also have to complete AT Level I, training available at: http://jko.jten.mil/courses/atl1/launch.html
OPSEC Training: OPSEC Fundamental Course (OPSE-1301) CBT, https://www.iad.gov/ioss/

11.2. GENERAL REQUIREMENTS:

11.2.1. The Contractor shall provide all plant, labor, equipment, tools, materials, supervision and transportation to perform all work associated with the repair /replacement of circulator pumps and motors as described. The work shall be performed in accordance with all manufacturer specifications and guidelines aswell as all federal, state and local codes subject to the terms and conditions of the contract.

11.2.2. Any measurements provided within this scope of work (SOW) are for government estimating purposes only. Contractor must field verify. The government is NOT responsible for failure to field verify all measurements and/or quantities.

11.3. DETAILS

11.3.1. INTERIOR WORK (TRAINING CENTER):

11.3.1.1. The Contractor shall isolate systems associated with circulation pumps CP-1, CP-2A, CP-2B, CP-5, and CP-6 by closing associated valves. The Contractor shall drain that portion of the system prior to doing any other work in this SOW. Contractor shall supply and install premium efficiency motors. Contractorshall check coolant levels post install and re-fill if necessary IAW manufactures specifications.
• Any drained water shall be disposed of by contractor IAW Federal, State and Local regulations and shall NOT be drained to sanitary sewer OR storm sewer. Any gaskets removed shall be presumed to be asbestos containing material unless documentation from installation is available that states they are non-ACM or sampling proves otherwise. As per 59 FR 33208 asbestos gaskets were never banned and are still legal to sell and purchase in the United States. If the original gaskets are to be disposed of it shall be IAW Federal, State and Local regulations.

11.3.1.2. The Contractor shall disconnect and remove three (3) chilled watercirculating pump motors (CP-1, CP-2A, CP-2B) and two (2) heating water circulating pump motors (CP-5, CP-6) located in the mechanical room 106. The Contractor shall save all five (5) electric motors and take them to be professionally re-wound and re-built by an approved electrical company, properly label each motor with mechanical ID tag (CP-1,2A,2B,5,6), and return motors onsite to be used as SPARES in the future. The Contractor shall submit proposal of which electric company will do the re-winding/rebuilding of the electric motors to the RFOS/QAR prior to the work being done. The five (5) pump housings shall also be rebuilt and the Contractor shall remove and replace all bearings, seals, and gaskets associated with all five (5) circulating pumps.

11.3.1.3. The Contractor shall then replace all five (5) circulating pump motors with all new one for one replacement units or approved equal. It is the responsibility of the Contractor that the new circulating pump motors meet or exceed the existing in Mechanical performance and Electrical requirements. If anotherapproved manufacturer is used that has different Electrical requirements, the Contractor shall be responsible for furnishing and installing new wire and new circuit breakers as required per the nameplate requirements of the new circulatingpumps. The technical details of the existing motors to be removed and replaced are as follows:

Unit Iden. Manufacturer Model Number Cat. Number Voltage/Phase/
Frequency HP FLA @ 480V/3ø
CP-1 U.S. Electrical Motors AD80A 6208-2Z-J/C3 208-230/460, 3ø, 60HZ 10 12.6
CP-2A Marathon Electric - High Efficiency Series 7VE254TTDX4026AD L E722 208-230/460, 3ø, 60HZ 15 19.2
CP-2B Marathon Electric - High Efficiency Series 7VE254TTDX4026AD L E722 208-230/460, 3ø, 60HZ 15 19.2
CP-5 U.S. Electrical Motors AD80A 6208-2Z-J/C3 208-230/460, 3ø, 60HZ 10 12.6
CP-6 Marathon Globetrotter 215TTDB6026 GT009 208-230/460, 3ø, 60HZ 10 12.2

11.3.1.4. After all five (5) pump motors have been replaced and all bearings, seals, and gaskets have been replaced in the pump housing, the Contractor shall open all of the valves previously shut off to fill the system back up. At thispoint, the Contractor shall verify and confirm that there are no leaks in the system, and correct any leaks as required.

11.3.1.5. The Contractor shall provide engraved plastic equipment tags on VFD's feeding circulating pumps CP-2A, CP-2B, CP-5, and CP-6 clearly identifying which VFD is feeding which circulating pump. The Contractor shall also provide engraved plastic equipment tags on the mounting frame of CP-5 and CP-6 motors. Permanent marker is not a suitable option. Match the ID tag located on the motor starter feeding circulation pump CP-1 for suitable labeling means.

11.4. WARRANTY:

11.4.1. The Contractor shall warranty the installation, materials, equipment, fixtures, and the systems which they compromise to be free from inherent defects or flaws in workmanship, operation, or design for no less than five (5) years, unlimited parts and labor.

11.5. CONTRACTOR RESPONSIBILITIES:

11.5.1. The Contractor shall have his/her field supervisor present before project closeout to confirm that all work completed was done in an acceptable manner including but not limited to materials, means and methods, and labor.

11.5.2. The Contractor shall have an official factory field representative of the new circulating pumps present at final inspection at no additional cost tothe Government for the commissioning and startup of the system. The Contractor shall coordinate with the factory representative and correct any issues with thesystem prior to project closeout.

11.5.3. The Contractor shall give three (3) copies in binders of all cut sheets, manufacturer warranty information to include points of contact, their phonenumbers and email addresses, and any other general information pertaining to this project to the RFOS, or his/her representative for distribution at the final inspection. Failure to have these binders done and at the final inspection will result in a delay of acceptance by the government and could result in delay of final payment to the Contractor.

11.5.4. The Contractor shall give three (3) copies in binders of O&M (Operations and Maintenance) Manuals of all materials associated in this SOW. Failure to have these binders done and at the final inspection will result in a delayof acceptance by the government and could result in delay of final payment to the Contractor.

11.5.5. The Contractor shall have 5 business days after the government conducts final inspection and accepts the project installation to remove ALL construction material from government property to include but not limited to excess material(s), storage trailer(s), roll-off dumpsters, tools, equipment etc.. Failure to comply could result in delay of final payment to the contractor.

11.5.6. The Government shall not be held liable for the Contractor's equipment, tools, materials, etc. that are stored at the building
.
11.6. CLEAN UP & REMOVAL

11.6.1. The contractor shall remove all contract-generated debris from the construction site and dispose of the debris off site at an approved landfill/facility. Disposal shall be in accordance with Local, State and Federal laws and regulations. In case of conflict among these laws and regulations, the most stringent law or regulation will apply. The contractor will NOT utilize government on-site dumpsters. The contractor shall provide their own roll-off dumpster. The Government will NOT be responsible for any unauthorized use of contractors roll dumpster.

12. THIS CONCLUDES THE REQUIREMENTS OF THIS SOW

CITE: https://www.fbo.gov/notices/ae407ee39b1c2598a9f22aadfb9f1ad3

SET-ASIDE: Total Small Business